Supreme Court Upholds Karnataka Electricity Regulatory Commission's Order Imposing Liquidated Damages and Tariff Reduction in Solar Power Project Dispute. The court held that the Scheduled Commissioning Date was 16.10.2017, and since injection of power into the grid occurred on 17.10.2017, the projects were delayed, justifying penalties under the Power Purchase Agreement.
3 May 2021The appeals arose from a judgment of the Appellate Tribunal for Electricity, which reversed an order by the Karnataka Electricity Regulatory Commissio...
