Search Results for "Termination of Developer"

Trending :

Bombay High Court Dismisses NHAI Appeals in Land Acquisition Compensation Disput...
Supreme Court Allows Appeal in Motor Accident Claim Case — Death Not Arising O...
Bombay High Court Dismisses Petitioner's Challenge to Arbitral Award in Commerci...
Bombay High Court Dismisses Appeal Against Attachment of Property in NSEL Scam C...
Bombay High Court Allows Appeal in Customs Classification Dispute — Bulk Pet F...

Search Results for "Termination of Developer"

4 result(s) found

Home Search Results

Scroll Down To Discover

Found 4 result(s)

Supreme Court

Supreme Court Dismisses Developer's Appeal in Slum Rehabilitation Project Due to Unconscionable Delay. The Court upheld the termination of the development agreement under Section 13 of the Maharashtra Slum Areas Act, 1971, emphasizing that the right to shelter under Article 21 cannot be held hostage by a developer's inaction.

30 Jul 2024

The present appeal arises from a dispute concerning a slum rehabilitation project in Borivali, Mumbai, under the Maharashtra Slum Areas (Improvement, ...

High Court

Bombay High Court Allows Writ Petition Challenging AGRC Order — Restores Termination of Developer for Non-Compliance with Mandatory Consents and No-Objection Certificate. Failure to Obtain Consent of 70% Municipal Tenants and Annexure-II from MCGM Justifies Termination Under Section 13(2) of Maharashtra Slums Areas Act, 1971.

10 Jun 2024

The Bombay High Court allowed a writ petition challenging the order of the Apex Grievance Redressal Committee (AGRC) which had set aside the terminati...

High Court

Bombay High Court Dismisses Developer's Challenge to Termination of Slum Rehabilitation Scheme Appointment — Upholds SRA's Power to Terminate Developer for Delay and Loss of Faith of Slum Dwellers. The court held that the CEO, SRA, validly exercised power under Section 32 of the Maharashtra Slums Act, 1971, and the termination was justified as the delay was attributable to the developer and the majority of slum dwellers had lost faith.

10 May 2024

The petitioner, a developer, challenged the termination of his appointment to implement a Slum Rehabilitation Scheme (SR Scheme) on a property owned b...

High Court

Bombay High Court Allows Writ Petition Challenging Apex Grievance Redressal Committee Order in Slum Rehabilitation Case. AGRC's Reversal of Developer Termination Set Aside for Non-Application of Mind and Violation of Natural Justice.

29 Apr 2021

The petitioner, Hanuman Nagar (Jogeshwari) SRA CHS (Proposed), is a society of slum dwellers residing on a plot in Jogeshwari, Mumbai. In 2006, the ma...

Full Name * Username * Mobile Number * Email Address * State/UT * City * Password * Confirm Password * Referral Code (Optional)