Supreme Court Allows Contractor's Appeal in Money Recovery Suit, Restoring Claims for Security Deposit, Overheads, and Loss of Profit. The Court Held That Abandonment of Work Was Not Established Under Contract Law, as Respondents Failed to Invoke Rescission Clause and Contractor's Actions Were Due to Delays and Modifications by Respondents.
30 Mar 2022The dispute involved a contractor who filed a suit for recovery of money against government respondents after a tender for a water supply scheme. The ...
